A. The Contractor is presumed to be familiar with all laws, ordinances, and regulations that may in any manner affect those engaged or employed upon the work, or materials or equipment used in or upon the work, or that may in any way affect the conduct of the work. The Contractor shall so conduct the work that conflict with any such laws, ordinances, or regulations will be avoided, and the Contractor shall save harmless the Contracting Authority and its representatives against any claims arising from violation thereof.
E. On non-Federal aid contracts, out-of-state contractors shall either file a surety bond, as provided in Iowa Code 91C.7, with the Division of Labor Services in the amount of $25,000 for a one-year period or shall provide a statement to the Division of Labor Services that they are prequalified to bid on contracts with the Department.
A. It shall be the Contractor's responsibility to have liability insurance covering all of the construction operations incident to contract completion and the Contractor must have on file with the Contracting Authority a current "Certificate of Insurance" prior to award of contract. The certificate shall identify the insurance company firm name and address, Contractor firm name, policy period, type of policy, limits of coverage, and scope of work covered (single contract or statewide). This requirement shall apply with equal force, whether the work is performed by persons employed directly by the Contractor including a subcontractor, persons employed by a subcontractor, or by an independent contractor.
B. In addition to the above, the Contracting Authority shall be included as an insured party, or a separate owner's protective policy shall be filed showing the Contracting Authority as an insured party.
C. The liability insurance shall be written by an insurance company (or companies) qualified to do business in Iowa. For independent contractors engaged solely in the transportation of materials, the minimum coverage provided by such insurance shall be not less than that required by Chapter 325A, Code of Iowa, for such truck operators or contract carriers as defined therein. For all other contractors, subcontractors, independent contractors, and the Contracting Authority, the minimum coverage by such insurance shall be as follows:
General Liability, Including: BODILY INJURY
Independent Contractors $500,000 Each Occurrence
Contractual Liability, $500,000 Aggregate
Products and Completed Operations PROPERTY DAMAGE
$250,000 Each Occurrence
BODILY INJURY AND PROPERTY DAMAGE
- COMBINED SINGLE LIMIT*
$750,000 Each Occurrence
*A comprehensive Catastrophe Liability Policy (Umbrella) can be used to aid in achieving the minimum required limits.
D. Failure on the part of the Contractor to comply with the requirements of this article will be considered sufficient cause to suspend the work, withhold estimates, and to deny the Contractor from receiving further contract awards, as provided in Article 1103.01.
The Contractor shall procure all necessary permits and licenses; pay all charges, fees, and taxes; and give all notices necessary and incident to the due and lawful prosecution of the contract.
A. The Contractor and Contract Surety shall indemnify and save harmless the Department, any affected third party, or political subdivision from any and all claims for infringement by reason of the use of any patented or copyright item.
B. The Contractor shall indemnify the Department for costs, expenses, and damages that may be obligated for payment by reason of an infringement during the prosecution of the work or after completion of the project.
A. Prior to final acceptance, if any repairs to the roadway are necessary due to construction or repair of drains or sewers, laying or repairing of pipes or conduits for telegraph or electric wires, or from any other disturbance of the roadway under permission issued by the Contracting Authority, the Contractor shall, upon notification by the Engineer, immediately make necessary repairs in conformance with the contract documents. These repairs shall be paid for per Article 1109.03, B; however, compensation will not be allowed when these repairs are made necessary by the Contractor's negligence or carelessness.
A. The attention of the Contractor is directed to the provisions of an act of Congress known as Title 23, United States Code, Section 1 and any other acts of Congress providing for road improvements. When the Federal Government is to pay all or any portion of the cost of an improvement or project, the construction work, although it is under the supervision of the Department and subject to laws of the State of Iowa, is also subject to the above mentioned acts of Congress and to all authorities. This construction work shall be subject to inspection by duly authorized agents of the Federal Government, but this inspection will not make the Federal Government a party to the contract.
Per Materials I.M. 107, all products of iron, steel, or a coating of steel which are incorporated into the work shall be of domestic origin and shall be melted and manufactured in the United States. The Engineer may allow minimal amounts of these materials from foreign sources, provided the cost does not exceed 0.1% of the contract sum or $2,500, whichever is greater. This amount shall include transportation, assembly, and testing as delivered cost of foreign products to the project.
In accordance with 46 CFR 381.7(b), on all Federal-Aid contracts, the Contractor agrees:
1. To utilize privately owned United States-flag commercial vessels to ship at least 50% of the gross tonnage (computed separately for dry bulk carriers, dry cargo liners, and tankers) involved, whenever shipping any equipment, material, or commodities pursuant to this contract, to the extent such vessels are available at fair and reasonable rates for United States-flag commercial vessels.
2. To furnish within 20 days following the date of loading for shipments originating within the United States or within 30 working days following the date of loading for shipments originating outside the United States, a legible copy of a rated, ‘on-board’ commercial ocean bill-of-lading in English for each shipment of cargo described in Article 1107.06, C, 1, to both the Contracting Officer (through the prime contractor in the case of subcontractor bills-of-lading) and to the Division of National Cargo, Office of Market Development, Maritime Administration, Washington, DC 20590.
3. To insert the substance of the provisions of this clause in all subcontracts issued pursuant to this contract.
A. In the performance of the contract, the Contractor shall comply with all applicable laws, rules, regulations, and ordinances governing safety, health, pollution, sanitation, noise control, and disposal of waste materials. The Contractor shall also make available such additional safeguards, safety devices, protective equipment, and take such actions as are reasonably necessary to protect the life and health of employees and the public. Violations of properly promulgated laws, rules, regulations, and ordinances reported to the Engineer by responsible agencies may result in the issuance of a suspension order until such time as the violation is corrected.
B. The Contractor shall make adequate provisions satisfactory to the Engineer for safety of inspectors, particularly at sampling locations. Provisions shall include guards for moving belts, pulleys, and wheels near the sampling point and a stable platform when sampling is to be done from an elevated location.
C. There shall be suitable retention dams in areas where approved liquid asphalt materials or asphalt binder are stored and used, to minimize pollution of nearby areas from effects of normal rains. The Contractor shall take other necessary precautions to prevent pollution of streams, lakes, ponds, reservoirs, and other areas with fuels, oil, bitumens, chemicals, or other harmful materials and to prevent pollution of the atmosphere from particulate and gaseous matter.
E. When directed by the Engineer, and with no additional compensation, the Contractor shall apply water to the construction area and haul routes, as necessary, to prevent the spread of dust. On Primary Roads and Primary Road extensions, on temporary Primary Road haul roads, and when designated in the contract documents construction areas adjacent to Primary Roads on which traffic is maintained, the Contractor will be paid for watering ordered by the Engineer at the rate of $60 per thousand gallons.
1107.08 PUBLIC CONVENIENCE AND SAFETY.
A. The schedule for removal of existing guardrail, warning devices, and other traffic control devices requires Engineer’s approval. The Contractor may be required to place temporary warning devices at locations where replacement features are not installed the same day as removal takes place.
B. The Contractor shall conduct the work to assure the least possible obstruction to access by the residents along the project. The Contractor shall schedule and conduct the work in such a way as to provide for their safety and convenience. The Contractor shall submit a construction staging plan to the Engineer for local access required to remain open. Relocated accesses shall be completed prior to removal of existing accesses. If a permanent access cannot be completed prior to removal of an existing access, the Contractor shall provide and maintain an alternate access. Work and materials required by the Engineer for public convenience and safety in excess of that provided for in the contract documents will be paid for per Article 1109.03, B.
C. Whenever it is practical to do so, the Contracting Authority will close the portion of the road under construction, provide a detour, and cause suitable detour signs to be erected to mark such detour.
D. When it is not practical for the Contracting Authority to close the road for construction, the Contractor will be expected to perform the work under traffic. The contract documents will indicate this fact and provide instruction for handling traffic through the work. Unless otherwise stated in the contract documents, all work shall be performed by the Contractor between the hours of 30 minutes after sunrise to 30 minutes before sunset.
E. Except when the contract documents indicate the road is to be closed, during all pavement widening, base widening, and HMA resurfacing work, traffic will be permitted to use the routes involved at all times and shall not be delayed unnecessarily. Where a pavement or base is being widened, the machine depositing material shall operate within the designated work area. Construction equipment may be stored within the right-of-way, as far from the traveled way as is practical, but the roadbed shall be free of Contractor's equipment during non-working hours. The work shall be planned and conducted to cause a minimum delay or interference with traffic.
F. When work on a traveled way necessitates diverting traffic from a work lane to another lane, material, mobile equipment, and vehicles shall occupy the work lane to the minimum extent and for the minimum time necessary, and non-mobile equipment shall be removed from the work lane promptly after its operation is completed in that lane.
G. On two-lane roadways, a work area shall be established only on one side of the roadway and there shall be no parking of vehicles or equipment on the opposite shoulder within 500 feet of the work area.
I. Parking of private vehicles on Interstate right-of-way will not be allowed. Parking of unattended equipment within the median or storage of equipment within 50 feet of the edge of pavement will not be allowed.
J. Materials stored within the highway right-of-way shall be placed to cause a minimum obstruction to traffic. Sidewalks, gutters, sewer inlets, and portions of highway adjoining the roadway under construction shall not be obstructed more than is necessary.
K. When the shoulder work is a part of the contract for work on a project open to public traffic during construction, the Contractor shall coordinate the operations so that the length and degree of pavement edge drop-off caused or partly caused by the operations are minimized.
1. Paved Shoulders (Partial or Full Width).
Construction shall be staged so no drop-offs exist at the pavement or shoulder edge when the adjacent lane is to be opened to traffic. The pavement edge drop-off requirement shall be satisfied with an HMA shoulder fillet. This fillet shall extend into the shoulder area a minimum of six times the thickness of the drop-off and shall be placed prior to the adjacent lane being opened to traffic. Compaction of the HMA fillet shall be a minimum of one coverage with a pneumatic tired roller per 1 inch of thickness. The fillet shall be removed prior to start of shoulder paving. The shoulder edge drop-off requirement shall be satisfied with a granular fillet, meeting the requirements of the following paragraph.
2. Granular Shoulders.
Construction shall be staged so no drop-offs exist at the pavement edge when the adjacent lane is to be opened to traffic. The drop-off requirements shall be satisfied with a shoulder fillet or full shoulder width of granular material according to Article 2121.03. The fillet shall extend into the shoulder area a minimum of six times the thickness of the drop-off and shall be placed prior to the adjacent lane being opened to traffic. Compaction of the fillet shall be a minimum of one coverage with a pneumatic tired roller per 1 inch of thickness.
M. Paved shoulder construction adjacent to existing travel lanes shall meet the following:
1. HMA Shoulder.
· Drop-offs greater than 2 inches will not be allowed when the adjacent lane is open to traffic,
· Place the final lift of HMA shoulder material within 48 hours of the previous lift.
2. PCC Shoulder.
Do not open adjacent lane until PCC shoulder is cured enough to support traffic control devices.
N. When the Contractor works on a bridge spanning a roadway or passageway, the Contractor shall take all necessary steps to protect the public using the facility below the bridge from falling debris, material, or construction equipment. The Contractor shall submit a safety procedure written plan to the Engineer prior to starting work. The plan shall include the following:
· Design of the means and methods used to provide protection.
· All assumptions used in the design.
Evaluation of the plan and design may require its preparation by a Professional Engineer licensed in the State of Iowa. If so, the costs will be paid for in accordance with Article 1109.03, B.
1107.09 BARRICADES AND WARNING SIGNS.
A. Barricades, warning signs, and other aspects of traffic control shall be in accordance with the contract documents. In providing adequate and proper traffic control, both the Contracting Authority and the Contractor have certain responsibilities.
1. Responsibilities of the Contracting Authority.
a. Advance Notification.
Whether a road is closed for construction or traffic is to be maintained during construction, the Contracting Authority will furnish, erect, and maintain such suitable advance warning signs, warning lights, and barricades as it deems appropriate outside the project area, in addition to those barricades and signs required to be erected by the Contractor. If necessary, where a road is closed for construction, a marked detour will be established.
b. Primary Road Intersections.
The Department will furnish, erect, and maintain such suitable advance warning signs, warning lights, and barricades as it deems appropriate where a Primary Road intersects a Primary project to provide a marked detour for through traffic using the intersecting Primary route or to provide advance notification to through traffic using the intersecting Primary Road and passing through the intersection. A marked detour may allow public traffic to use the intersection.
c. Secondary Projects.
Where a Secondary Road project requires work within a Primary Road right-of-way or extension of the right-of-way across the Secondary Road, the Primary Road shall be protected as a Primary project through which traffic is maintained. The Department will furnish, erect, and maintain such suitable advance warning signs, warning lights, and barricades as it deems appropriate. The County will notify the Department so this protection can be provided for Secondary projects.
Except when there is an item for traffic control, all signs and traffic control devices (except pilot car signs and flagger signs) will be made available to the Contractor at a nearby site designated by the Engineer. They will be furnished by the Contracting Authority. Replacement materials will also be furnished as necessary.
e. Additional Notification.
Any additional signs, barricades, or notification beyond the project area deemed appropriate by the Engineer will be the responsibility of the Contracting Authority.
f. Regulatory and Warning Signs.
The Contracting Authority will erect prior to construction any additional special regulatory or warning signs required due to construction that are located outside of the project limits. This does not apply to warning and regulatory signs specifically required for traffic control zones necessary for construction activities defined in the contract documents.
By agreement, the Contracting Authority will accept responsibility for maintenance of signs and barricades when work is suspended for 30 calendar days or more, or when such time of suspension is anticipated.
2. Responsibilities of the Contractor.
1) The Contractor shall be responsible for placing and maintaining proper barricades, warning signs, and other traffic control devices on the project, and the Contractor shall take every reasonable precaution to prevent traffic from interfering with the work and to prevent the work from interfering with the traffic; and shall take every reasonable precaution to provide for safety of the general public traveling to, through, within, along, and across the project. Where the road is closed for construction, the Contractor shall take every reasonable precaution to protect the work and equipment and to provide for safety of the public. When traffic is to be maintained through the construction, the Contractor shall erect and maintain all signs; furnish, erect, and maintain all other traffic control devices and other safeguards; provide all flaggers necessary to protect the traveling public. Payment for this work will be in accordance with Article 2528.05.
2) The Contractor shall furnish, erect, and maintain ROAD WORK AHEAD and END ROAD WORK signs at the mainline limits of individual work areas on highway construction or contract maintenance projects where traffic is maintained through a traffic control zone. The ROAD WORK AHEAD sign shall be placed to identify where traffic enters a traffic control zone. The END ROAD WORK sign shall be placed to identify where traffic leaves a traffic control zone and be located at least 500 feet beyond the work area. Should more than one contractor be working on the project, the Engineer will assign the responsibility for these signs.
b. Intersecting Local Public Roads.
1) When a road closed for construction intersects other local public roads within a project, the Contractor shall erect and maintain barricades and warning signs in accordance with the contract documents. Payment for this work will be in accordance with Article 2528.05.
2) The responsibility described in the previous paragraph is intended to be in addition to actions of the Department described in Article 1107.09, A, 1, b.
c. Entrance from Local Public Roads.
On local public roads open to traffic during construction, the Contractor shall erect and maintain signs in accordance with the contract documents. When scarification is part of the contract, ROUGH ROAD signs shall also be erected on the shoulder of the road under construction at local public road intersections. These signs shall be erected, moved when appropriate, and maintained by the Contractor until the scarified areas are covered with the new surface material. Payment for this work will be in accordance with Article 2528.05.
d. Shoulder Drop-Offs.
Drop-offs at paved and granular shoulders shall be treated as provided in Article 1107.08. All other drop-offs shall be handled in accordance with project plan requirements.
e. Sign Removal.
1) The Contractor shall not remove, move, or obstruct any regulatory, guide, or warning sign without approval of the Engineer. If these signs interfere with construction, approval of the Engineer shall be obtained prior to removal; temporary re-erection, if appropriate; and re-erection by the Contractor.
2) The Contractor shall be responsible for erecting, moving, maintenance, and removal of all signs necessary to protect the work area and uncompleted work and signs required elsewhere by the contract documents.
3) If the Contractor inadvertently damages a regulatory, guide, or warning sign, or makes it ineffective, the Contractor shall correct it and promptly notify the Engineer.
f. Availability of Signs.
The Contractor shall pick up signs and barricades furnished by the Contracting Authority at the site designated and shall return them when the work is completed.
g. Traffic Control Item.
When there is a contract item for traffic control, the Contractor shall furnish all signs, barricades, channelizing devices, and other traffic control identified in the contract documents.
h. Commencement of Responsibility.
The Contractor shall assume the responsibility required by this article because of the operations concurrent with possession of the work site or right-of-way through moving of equipment, machinery, tools, or materials thereon and in all cases when the work is commenced.
The reflective surfaces of signs and traffic control devices shall be washed, as described in Article 2528.03, L, and shall be clean at the time of initial installation on a project.
j. Traffic Control in Place.
At any time signs, barricades, or other traffic control devices are in place, for which the Contractor is responsible, the Contractor provide the Engineer the following information at the preconstruction conference or before work commences:
1) The name and telephone number of a 24 hour emergency response person for traffic control (answering services are not acceptable); so that repair or maintenance of these devices can occur promptly, within 2 hours and
2) The name and telephone number of the traffic control technician in responsible charge of the traffic control for the project per Article 2528.01, C.
B. The contract documents may require placement, maintenance, and removal of temporary and permanent pavement marking and temporary delineators. This work shall be in accordance with requirements of Section 2527.
C. An additional flagger shall be stationed at public road intersections or crossings within the work area, if necessary, to prevent vehicles from entering the work area against the flow of traffic. When traffic control is incidental, additional flaggers will not be paid for separately.
D. The Engineer may require additional flaggers or other safeguards because of unusual or changed conditions, including suspensions and delays. Except when the need arises from the Contractor's actions or inactions, this will be paid for in accordance with Article 1109.03.
A. When the use of explosives is necessary for the prosecution of the work, the Contractor shall exercise the utmost care not to endanger life or property, including new work. The Contractor shall be responsible for all damage resulting from use of explosives.
B. All explosives shall be stored in a secure manner in compliance with all laws and ordinances and in quantities maintained at a practical minimum. Storage places shall be clearly marked. Where no local laws or ordinances apply, storage shall be provided satisfactory to the Engineer and, in general, not closer than 1000 feet from the road, building, camping area, or place of human occupancy.
C. The Contractor shall notify each public utility company having structures in proximity to the site of the work of the Contractor's intention to use explosives. This notice shall be given sufficiently in advance to enable the companies to take such steps as may be necessary to protect their property from damage.
B. The Contractor shall take suitable precautions to prevent damage to telephone, telegraph, and electric transmission lines along the highway and to pipes, conduits, and other underground structures.
D. The Contractor shall be responsible for damage to property resulting from the performance of the work; however, this responsibility shall not extend to damage to fences, telephone, telegraph, or electric lines occupying the right-of-way unlawfully, provided due caution has been used in removing them.
E. The Contractor shall carefully protect from disturbance all land monuments and property marks until an authorized agent has witnessed or otherwise referenced their location, and the Contractor shall not remove them until so directed.
A. The parties agree that it is their intent that there be no third-party beneficiaries to this contract. No provision of this contract; or of any addendum, materials instructional memorandums, plan, proposal, special provision, standard specification, developmental specification, supplemental specification, or general supplemental specification; shall be construed as creating any third-party beneficiaries.
B. The Contractor shall indemnify and save harmless the Contracting Authority and other agencies which have concurred in the award of the contract, as well as their officers and employees, from all suits, actions, or claims of any character, except as provided in the next sentence. Indemnity shall not, however, extend to acts or omissions for which the Contracting Authority is solely responsible, though it shall extend to those claims, actions, or suits in which the Contractor, Subcontractor, or either's employee or agent, and the Contracting Authority are alleged to be, or could be, jointly or concurrently liable. Any funds due said Contractor under the Contractor's contract as may be considered reasonable and necessary by the Contracting Authority for such purpose may be retained for the use of the Contracting Authority; in case no money is due, the Contractor's surety may be held until such suit or suits, action or actions, claim or claims have been settled and suitable evidence to that effect furnished to the Contracting authority, except that money due the Contractor will not be withheld when the Contractor produces satisfactory evidence of insurance covering the claim, action, or suit.
C. The Contractor's responsibility for providing warning devices required by Article 1107.09 to avoid damages or injuries to the traveling public on any portion of the road covered by the contract shall not cease until the work on such portion has been released by the Engineer. A "release" in this context means a written statement by the Engineer stating that the Contractor may cease to maintain barriers and lights, that the road may be opened to traffic, and that the Contractor is relieved of further maintenance of that portion of the road. This release shall not constitute an acceptance of the work.
A. When any substantial portion, part, or feature of a contract is completed to the extent that its stability and integrity is not dependent upon completion of other items or work required in the contract, that portion, part, or feature may be released by the Engineer, after conferring with the Contractor, and opened to traffic or received for public usage prior to final approval and acceptance of all work involved in the contract. The Contractor will not be responsible for damages due to the elements or the general wear of traffic to those portions, parts, or features of the road which have been released by the Engineer. The Contractor will be responsible for any damages which may be caused by defective work or failure to comply with the contract documents.
B. The above provisions relating to a release by the Engineer will be applicable only to those portions, parts, or features of a contract for which the Engineer has furnished to the Contractor a written release.
The Contractor will be responsible for care and maintenance of partially completed work and finished work on any portion of the road until the Contractor has been released by the Engineer from this responsibility. It shall be the Contractor's responsibility to adjust the operation or method of operation to prevent any damage of any nature to any portion of partially completed or completed work, except for damage to work in officially designated disaster areas where the damage results from Acts of God for which the designation is made. Repair work shall be done promptly upon being so ordered by the Engineer.
A. The Contracting Authority will endeavor to have all necessary adjustments made to public or private utilities within or adjacent to the limits of construction prior to construction activities, except those requiring coordination with the Contractor. Utility facilities have been plotted from available surveys and records, and shall be considered approximate. Other utilities may exist and their location may not be presently known or identified on the plans. The Contractor shall notify Iowa One-Call at 1.800.292.8989 to identify the location of all underground utility facilities within the construction area.
B. The Contractor shall determine the exact location of all public and private utility facilities located within the construction area to avoid damage in accordance with Iowa Code 480.4. The Contractor shall have considered in their bid all permanent and temporary utility appurtenances in their present or adjusted positions as shown in the contract documents. For projects not developed under 761 IAC 115.25 and not designated as POINT 25 projects in the contract documents, additional compensation will not be allowed for any delays, inconvenience, or damage sustained by the Contractor due to any interference from the utility appurtenances or their operation or relocation.
C. Where existing utility facilities are shown in the contract documents or encountered within the construction area, the Contractor shall notify the utility company prior to beginning construction activities. The Contractor shall be responsible for notifying utilities and conducting work near utility facilities, required by Iowa Code 480.4.
D. Any system for supplying water, gas, power, or communications; a storm sewer, sanitary sewer, drainage tile, or other system for transmitting liquids; a pipeline system; traffic signalization system; and lighting systems within the limits of the proposed construction, which are to be adjusted, are to be moved by the utility company at their expense, except as otherwise provided for in the contract documents.
E. The Contractor shall cooperate with utility companies in their adjustment operations so that these operations may progress, the duplication of adjustment work may be reduced, and that services rendered by those parties will not be interrupted.
F. Where the Contractor's operations are adjacent to properties of railway, communication, or power companies, or are adjacent to other utility facilities where damage might result in considerable expense, loss, or inconvenience, work shall not begin until all arrangements necessary for protection of the facilities have been made.
G. In the event of interruption to utility services as a result of accidental breakage or as a result of being exposed or unsupported, the Contractor shall promptly notify the proper authority and shall cooperate with the authority in restoration of service. If a utility service is interrupted, repair work shall be continuous until service is restored.
H. Primary projects developed under 761 IAC 115.25 and designated as POINT 25 projects in the contract documents, where the utility company's adjustment is dependent on work by the Contractor, the Contractor shall provide the Contracting Authority and the utility company a good faith notice 14 calendar days and a confirmation notice not less than 3 working days before the Contractor's work will be complete and ready for the utility company to begin its work. If the utility fails to complete the adjustment of its facilities and fails to submit or comply with its accepted work plan as referenced in the Utility Status Report in the contract documents, and these failures result in a delay to the Contractor or causes damages to be incurred by the Department or Contractor, the utility may be liable for costs and damages incurred as a result of its failure to perform.
In carrying out any of the provisions of the contract, or in exercising any power or authority granted to any agent or representative of the Contracting Authority thereby, there shall be no liability upon such agent or representative, including the Engineer or authorized assistants, either personally or as an official of the Contracting Authority, it being understood that in such matters the Engineer acts as the agent and representative of the Contracting Authority.
A. The Contracting Authority shall not be prevented by any measurement, estimate, or certificate made either before or after the completion and acceptance of the work and payment therefore from showing the true amount and character of the work performed and materials furnished by the Contractor, or from showing that any such measurement, estimate, or certificate is untrue or incorrectly made, or that the work or materials do not, in fact, conform to the contract.
B. The Contracting Authority shall not be prevented, notwithstanding any such measurement, estimate, or certificate and payment in accordance therewith, from recovering from the Contractor and the Contractor's sureties such damages as it may sustain by reason of the Contractor's failure to comply with the terms of the contract. Neither acceptance by the Contracting Authority, or any representative of the Contracting Authority, nor any payment for or acceptance of the whole or any part of the work, nor any extension of time, nor any possession taken by the Contracting Authority, shall operate as a waiver of any portion of the contract, or for any power herein reserved, or any right to damages herein provided. A waiver of any breach of contract shall not be held to be a waiver of any other or subsequent breach.